Terms & Conditions

Last Updated: January 19, 2026

1. Agreement to Terms

These Terms and Conditions constitute a legally binding agreement made between you, whether personally or on behalf of an entity ("you") and Buildova Ltd ("we," "us" or "our"), concerning your access to and use of the buildova.co.uk website as well as any other media form, media channel, mobile website or mobile application related, linked, or otherwise connected thereto (collectively, the "Site").

By accessing the Site, you agree that you have read, understood, and agree to be bound by all of these Terms and Conditions. If you do not agree with all of these Terms and Conditions, then you are expressly prohibited from using the Site and you must discontinue use immediately.

2. Use License

Permission is granted to temporarily view the materials (information or software) on Buildova Ltd's website for personal, non-commercial transitory viewing only. This is the grant of a license, not a transfer of title, and under this license you may not:

• Modify or copy the materials
• Use the materials for any commercial purpose, or for any public display (commercial or non-commercial)
• Attempt to decompile or reverse engineer any software contained on the Site
• Remove any copyright or other proprietary notations from the materials
• Transfer the materials to another person or "mirror" the materials on any other server

3. Services

Buildova Ltd provides construction services including but not limited to:

• Refurbishment and renovation work
• New build construction projects
• Day work subcontracting
• Price work subcontracting
• Property maintenance services

All services are subject to availability and our acceptance of your project. We reserve the right to refuse service to anyone for any reason at any time.

4. Quotations and Estimates

All quotations provided are estimates based on the information available at the time. Final costs may vary based on:

• Changes in project scope
• Unforeseen site conditions
• Material price fluctuations
• Additional work requested by the client
• Delays caused by factors outside our control

Written quotations are valid for 30 days unless otherwise stated.

5. Payment Terms

Payment terms will be agreed upon in writing before commencement of work. Standard payment terms typically include:

• Deposit required before work commences
• Stage payments for larger projects
• Final payment upon completion and client satisfaction
• Payment methods: Bank transfer, cheque, or as agreed

6. Project Timeline

We will provide estimated completion dates for all projects. While we make every effort to complete work on time, timelines may be affected by:

• Weather conditions
• Material delivery delays
• Client-requested changes
• Unforeseen site conditions
• Third-party delays (utilities, inspections, etc.)

7. Warranties and Guarantees

We warrant that all work will be carried out in a professional and workmanlike manner in accordance with industry standards. Specific warranties on workmanship and materials will be provided in writing for each project.

Warranties do not cover:

• Normal wear and tear
• Damage caused by misuse or neglect
• Work performed by third parties
• Acts of nature or extreme weather conditions

8. Client Responsibilities

The client agrees to:

• Provide accurate information about the project
• Ensure site access as agreed
• Obtain necessary permissions and permits where applicable
• Make payments according to agreed terms
• Notify us promptly of any concerns or issues

9. Liability Limitations

Buildova Ltd carries appropriate public liability insurance. However, we shall not be liable for:

• Indirect or consequential losses
• Loss of business or profits
• Damage to property not directly related to our work
• Issues arising from pre-existing conditions not disclosed

10. Health and Safety

We comply with all relevant health and safety regulations. We require clients to:

• Keep children and pets away from work areas
• Not interfere with equipment or materials
• Report any safety concerns immediately
• Follow any safety instructions provided

11. Cancellation and Changes

Either party may cancel or postpone work by giving reasonable notice. Cancellation charges may apply to cover costs already incurred. Changes to agreed work must be requested in writing and may result in revised quotations and timelines.

12. Disputes

In the event of any dispute, we encourage resolution through direct communication. If this is not possible, disputes will be handled according to the laws of England and Wales.

13. Intellectual Property

Unless otherwise stated, Buildova Ltd and/or its licensors own the intellectual property rights for all material on the Site. All intellectual property rights are reserved.

14. Privacy

Your use of our Site is also governed by our Privacy Policy. Please review our Privacy Policy, which also governs the Site and informs users of our data collection practices.

15. Modifications

We reserve the right to modify these terms at any time. Changes will be effective immediately upon posting to the Site. Your continued use of the Site following the posting of revised terms means that you accept and agree to the changes.

16. Governing Law

These terms and conditions are governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts in that location.

17. Contact Information

If you have any questions about these Terms and Conditions, please contact us: